O'Rourke v. Burke

Ryan, C. This action was brought in the Douglas county district court- by John N. Burke against D. A. Way, the principal, and John J. O’Rourke, his surety, on a building contractor’s bond which had been executed to Mr. Burke. There were alleged in the petition several failures of the principal to perform according to the terms of his contract, followed by a prayer for judgment for $1,500, the penal sum named in the bond sued upon. There was a verdict for the sum of $950, on which the judgment now complained of was duly rendered against O’Rourke, who alone «defended. The contract for the faithful performance of the terms of which the above bond was entered into was dated-May 12, 1891. It required D. A. Way, on or before June 24, 1891, to build to completion a certain hotel and hand ball court according to the requirements of certain plans and specifications therein referred to. The principal ■contentions which we shall consider were as to the manner in which payments of the amounts due under such contract should be made. The contract itself was prepared for signature by filling out the blanks in a printed form. This -was done by an architect in such a manner as to render applicable Mrs. Quickley’s description of bad language as an [824] "abusing of-God’s patience and the king’s English.” It is a well recognized rule that where a printed form has-been filled out the written language controls that which is printed. The difficulty of determining just what-was agreed can be illustrated only by quoting the exact written language with its defective orthography, its misplaced capital letters, and absence of punctuation, just as they exist. The provisions as to payments were in the following partly printed and partly written language, that which was wrilten being indicated by the use of italics: .. “ John Burke * * * will well and truly pay, or cause to be paid unto the part— of the first part or unto-D. A. Way heirs executors administrators or assigns the sum of $2143.80 cents Dollars lawful money of the’United States of America in manner following: On - 1891,. ‡%143.80 cents — the first payment in 2 weeks or the pay Role Every two weeks as the work progresses and John Burk Reserves the wright to asomes the lumber Bills But.to keep Bach two hundred dollars untill the work is all complete and excepted when the building — is all complete and after the-expiration of 10 days when all the Drawings and Specifications have been, returned to J. W. Boileau Architect: "Provided that in each case of the said payments a certificate shall be obtained from and signed by J. W. Boileau Architect to the effect that the work is done in strict accordance with Drawings and Specifications and that he <U W. Boileau considers the payment properly due,” etc. In the petition it was alleged "that during the progress-of said work the plaintiff paid to the said Daniel A. Way,, upon the written certificate of plaintiff’s architect, the sura of seven hundred and sixty-eight dollars and five cents-, ($768.05).” In the answer there was pleaded an entire failure to require a certifícale of the architect showing that, the work had been done in the manner required, or, that-J. W. Boileau considered payments properly due. By reply the plaintiff denied that he was required by the terms825 of the contract to make said payments to the plaintiff for the purpose of paying the pay-roll only upon the production of a certificate from the architect, and alleged the fact to be that no certificate was by the terms of said' contract required to be obtained from the said architect for the payment of the amount necessary for the pay-roll every two weeks during the progress of the said work, and that each and every payment made to the contractor during the progress of said work was made upon orders signed by the architect. At random from the bill of exceptions, we quote some of the orders on which payments were made, to-wit: • “Mr. John Burke, please pay to the contractor,' D. A. Way, the sum of $100.00, as estimate on building. “J. W. Boileau.” “Mr. John Bork, please pay to J. C. Pottinger the sum of $25.40. J. W. Boileau, Superintendent. Charge the same to plaster account.” “Mr. John Bork, pay P>. A. Way five dollars on account O. K. J. W. Boileau, Superintendent.” “John Bork, please pay to D. A. Way the sum of $246.90. J. W. Boileau on building, Superintendent.” The above are samples of such orders as were in evidence, and from the testimony of witnesses and the averments of the reply above referred to it is quite evident that whatever else was issued by Mr. Boileau precedent to payments were in the same style. It must therefore be accepted as beyond question that each payment on the payrolls was made without obtaining a certificate from the architect as to how the work had been done and that he considered the said [ ayment properly due. As we understand the written language quoted from the contract, the terms were that the first payment was to be in two weeks to D. A. Way, or the pay-roll (to be paid D. A. Way) every two weeks as the work progressed; in other words, [826] Mr. Burke was to make payment according to the payrolls at intervals of two weeks as the work progressed. By the printed proviso it was further required that as evidence that each pay-roll showed correctly what was payable, there should be obtained a certificate of the architect that he considered the sum shown by the pay-roll as at the time properly due. If at the time this suit was brought the plaintiff had in his hands money due for labor done under the above contract he could not recover from the surety the amount withheld from the principal. If that money was at one time in his hands and he paid it to the principal he must, to entitle himself to a recovery as against the surety pro tanto, be able to show that the payment to the principal was not in disregard of the terms of the contract as to which the surety sustained the relation of guarantor. As was said in Brennan v. Clark, 29 Neb., 385: “The rule is well settled that a surety is bound in the manner and to the extent provided in the obligation executed by him, and no further.” See, also, Bell v. Paul, 35 Neb., 240, wherein it was held under a contract restricting payments to eighty-five per cent of the amounts of work done as shown by estimates of the architect, that payments in excess of eighty-five per cent without consent of the surety or estimate by the architect discharged such surety. The same principle was recognized in Hayden v. Cook, 34 Neb., 670. In the case at bar it was not shown that there was ever made by the architect a certificate which would justify payment of the amount of any fortnightly pay-roll. Payment without such certificate was, as against the surety, as though there was no payment whatever. As it is undisputed that the verdict was reached upon the assumption that such payments as were made upon the pay-rolls were properly made, the judgment of the district court must be reversed. As to the construction to be given to the language whereby Mr. Burke reserved the right to assume the lumber bills, we áre of opinion that the district court properly [827] held that the lumber bills contemplated were such as were known to Mr. Burke, for it could hardly have been expected that he would undertake to exercise a right of option as to that of the existence of which he was ignorant. The amount of the pay-rolls and of the lumber bills in the aggregate assumed, however, should not have been in excess of $1,943.80; that is to say, there should have been held back by Burke the sum of $200. On his theory, as we understand it, this -was done. In the contract between Mr. Way and Mr. Burke was the following provision: “Third —Should the proprietor at any time during the progress of the said works require any alterations of, deviations from, additions to, or omissions in the said contract, specifications, or plans, he shall have the right and power to make such change or changes, and the same shall in noway injuriously affect or make void the contract, but the difference for work omitted shall be deducted from the amount of the contract*by a fair and reasonable valuation; and for additional work required in alterations the amount based upon the same prices at which the contract is taken shall be agreed upon before commencing additions as provided and hereinafter as set forth in article No. 6, and such agreement shall state also the extension of time (if any) which is to be granted by reason thereof.” In the construction of the building changes were made which involved greater cost than was originally contemplated, but these changes in advance were arranged for between Mr. Way and Mr. Burke, consistently with the provisions of their contract in respect thereto. The surety nevertheless contends that the departure from the plans and specifications operated to relieve him of liability. The instruction of the court, very aptly defining the rights of the surety in this respect, was in the following language: “You are instructed that under the contract the parties thereto had a right to agree to alterations, additions, or changes in the building without avoiding the contract, but that, in such [828] case, if such changes or additions increased the cost of the building, the amount thereof should be added to the contract price and the plaintiff would become liable to pay for such increased cost; provided, however, that if such changes unreasonably increased the cost of the building beyond what might reasonably be within the contemplation of the parties at the time of-making the contract, such unreasonable changes would have the effect of discharging the surety. It is for you to say whether the changes and additions shown by the evidence were unreasonable-or such as would not ordinarily in a building contract of .this character be considered as likely or probable. . If you believe from the evidence, that such changes and additions were unreasonable, you should find for the defendant O’Rourke. If, however, you believe, considering all of the circumstances, that they' were reasonable and such as would be likely to arise in contracts of this nature, .the defendant, O’Rourke would not on that account be discharged. In considering whether the changes were reasonable or not you may, in connection with all the circumstances, take into consideration the relative cost of the building, as originally planned, and of the amount of the changes made in the plans.” The surety could not properly ask, in the face of express provisions admitting of changes being made, that he should be protected against such changes, so long as they were reasonable and such as when the contract was made might have been contemplated as falling within.the reservation of the right to make changes as above expressed; For the reasons hereinbefore stated the judgment of the district court is Reversed.