Thilemann v. City of New York

O’BRIEN, J. The plaintiff seeks to recover upon five separate ■causes of action based upon claims which arose in the course of his performance of a contract entered into with the city of New York whereby he agreed to construct a sewer in East 187th street and in ■adjoining streets and avenues. For the work performed a certificate was given to the plaintiff amounting in the aggregate to the sum of $66,533.14, of which he was paid $63,372.67, the sum of $2,611.47 being retained as repairing security, and the sum of $549 being deducted by the city as damages for overtime. The plaintiff’s first cause of action is to recover this sum of $549, he claiming that it was wrongfully deducted, and that the defendant had unlawfully delayed him. The contract provided that the work should be completed within 350 days, ex■clusive of Sundays and holidays and days excepted by the contract, unless more time was required for certain additional work, when it was to be extended proportionally; that the time was to be compared with the aggregate time of inspectors, and not construed as consecutive days; and that the city might deduct as liquidated damages for the noncompletion of the work the sum due for “inspector's wages — 775 — (four dollars a day) for each and every day the aggregate time of all the inspectors * * * may exceed the time stipulated.” There was no provision in the contract for an allowance of time for delays occasioned by the act, omission, or fault of the defendant, nor that a certificate of such delays be given, but for unnecessary delay and nonperformance by the plaintiff the city was given the right to abrogate the contract. The defendant’s evidence, in the form of certificates and letters and testimony of those connected with the work, shows that the inspector’s time was 978)4 days; that 139)4 days were allowed for unsuitable weather, and that 352 days were allowed for delays occasioned by the city; leaving as overtime, above the 350 days stipulated in the contract, 137)4 days to be charged the contractor, which, at $4 a day, amounted to $549, the sum deducted. The evidence offered by the plaintiff was directed to showing that 510 instead of 352 days should be allowed for the delays occasioned and recognized by the city; and, moreover, that in addition the city was responsible for loss of time in the execution of the contract after the work was awarded, owing to questions which had arisen regarding the debt limit and other matters. It was further claimed by the plaintiff upon the trial that the computation made by the defendant and the view taken by the court were erroneous in confusing “inspector’s days” and calendar days. The main insistence of the plaintiff, however, was that the first cause of action should not be submitted to the jury, but that the court should direct a verdict in his favor, and to the refusal of the court so to do an exception was taken. This exception is urged on our attention upon this appeal, and it is contended that, the prosecution of the work having concededly been hindered and delayed by the defendant’s fault, this abrogated the time limit of 350 days prescribed in the contract, and no deduction should be made by the city, the plaintiff having performed the work within a reasonable time. If this first cause of action was one properly submitted to the jury, then, upon the evidence adduced, their verdict in defendant’s favor should not be disturbed. We think, however, that the plaintiff’s contention that the conceded delays occasioned by the city abrogated the provision of the contract with respect to damages for overtime, and thereafter the contractor might complete within reasonable time, is correct. No provision of the contract permitted an allowance for delays by the city, and in the absence of such a provision it is inconsistent to hold the plaintiff for overtime in performing, and, on the other hand, compel him to allow delay on the part of the city. Dady v. Mayor, 57 Hun, 456, 10 N. Y. Supp. 819; Weeks v. Little, 89 N. Y. 566; Phelan v. Mayor, 119 N. Y. 86, 23 N. E. 175. In Dady v. Mayor, supra, it was said: “When the city caused any substantial delay in the work, it lost the right to charge the contractor with the stipulated liquidated damages for overtime, and could only insist that the time of completion should be reasonable." Here the city did not claim nor attempt to establish that there was any unreasonable delay by the contractor, but it stood upon its rights given by that provision of the contract which prescribed the time limit and damages. We think, therefore, that the city was not justified in deducting the sum — 776 — mentioned or any sum as damages for overtime, and that for the amount retained as such damages a verdict should have been directed in plaintiff’s favor. It is unnecessary to discuss the subject of the proper manner of computing the-overtime, in view of the conclusion at which we have thus arrived with respect to the first cause of action. The second cause of action is to recover $1,836 for increased cost occasioned by the defendant permitting other contractors to place filling upon the line of his sewer construction, thus necessitating extra labor. That such extra work was performed is not disputed; but the defendant’s claim is that the plaintiff was aware that the filling would be placed upon the avenues by those who preceded him, that the contract so indicated, and that the city, in any event, allowed him for the delay thereby occasioned. Allowance merely for delay, however, would not compensate the plaintiff for the work performed in removing the filling. Nor do the terms of the contract referred to show that the city was not to be liable for extra work occasioned by its permitting others to place filling which it would be necessary for the plaintiff to remove. The particular provisions relied upon by the city in this respect state: “It is further agreed that, should postponement or delay be occasioned by the precedence of other contracts on the line of the work which may be either let or executed before or after the execution of this contract, no claim for damages therefor shall be made or allowed, nor shall any claim for damages be made or allowed in consequence of the street or adjoining sewer not being in the condition contemplated by the parties at the time of making the contract, except that, if the contractor shall be delayed * * * by reason of the street or adjoining sewer not being in such condition, such allowance of time shall be made him as shall be deemed reasonable, * * * and incumbrances or obstructions which may be upon the line of the work when it is begun or may be thereafter placed there shall, if directed by the engineer, be removed by the contractor at his own expense.” The facts show that the contract was awarded the plaintiff in November, 1897, and executed October 26, 1898, for the construction of a sewer in and along various streets and avenues, including portions of Crotona avenue and Arthur avenue. On August 11, 1897, a contract was awarded by the city to Alfred P. Whitton for regulating and grading Crotona avenue, including that part thereof in which the plaintiff was to construct the sewer; and on March 10, 1898, a contract was awarded by the city to George Clarke for the regulating and grading of Arthur avenue, including that part thereof in which the plaintiff was to construct his sewer. Under their contracts with the city, the said Whitton and Clarke proceeded to regulate and grade the said avenues, and in so doing filled in for a considerable depth before the plaintiff had reached with his sewer those portions of the avenues. The work of these contractors was not begun when the plaintiff looked over the location, and when it was begun the plaintiff notified the city and objected to the filling in, for the reason that it would be necessary for him to excavate the same for his sewer. The exact amount of filling removed by the plaintiff was testified to by him, and the cost thereof, and the city does not dispute the sum named of $1,836. We think that the contract did not free the city from liability for work caused in the manner indicated. The filling in of the avenues by others to whom had been awarded contracts for regulating and grading — 777 — such avenues was not in the nature of an “incumbrance or obstruction” contemplated by- the parties, nor was it a “change of condition” such as could have been contemplated. By its own act in permitting the other contractors to proceed with grading and regulating the very streets and avenues in which the plaintiff was directed to construct his sewer in accordance with the condition of the locality as it originally was, the city increased the plaintiff’s work, and for the additional cost it should respond in damages. Although not obliged to wait until he had constructed his sewer in those avenues, it should, after directing against his protest such work to be done, reimburse him for the expense thereby entailed upon him. Rogers v. City, 71 App. Div. 618, 76 N. Y. Supp. 1029, affirmed, but not yet officially reported, Court of Appeals (66 N. E. 1115), February term. In the Rogers Case also a contractor for sewer work was obliged to remove filling placed on the line of his work by a contractor who preceded him in the avenue, and for the increased cost a verdict was directed in plaintiff’s favor, and the judgment so entered was affirmed by this court and the Court of Appeals. Upon the authority of that case, therefore, the court here should, as the facts are not disputed, have directed a verdict in plaintiff’s favor. The third cause of action is to recover the sum of $13,306.63 for damages and increased cost occasioned by false representations of the city as to the existence of a sewer at the Southern Boulevard. The map submitted to the plaintiff by the city was put in evidence to show that such representation was made. One of the city’s engineers testified that he was familiar with plans and profiles of sewer contracts, and with the meaning of the different marks and colors used, and that the two black lines upon the map turning around in Southern Boulevard (at the intersection with East 187th street) indicate work that has been finished at that point, and the figures indicate the size of the sewer; that he should consider that work as already constructed and the work to connect with it; that a proposed sewer would not be so indicated. Previous to this testimony the court had refused to permit a contractor to testify as to the meaning of the lines referred to upon the map, and exception was taken. The advertisements for the contract, it was shown, instructed bidders to visit the locality as well as to examine the maps and specifications, and the plaintiff personally went to the place, and saw no indications of manholes of the sewer, but, he says, concluded that, as the boulevard was not graded, the manholes were covered. As matter of fact, there was no sewer at the place indicated on the map. Had there been one available and serviceable to the plaintiff, it was testified that a drainage would have been established which would have avoided expensive pumping that was done, and for which the plaintiff asks damages. The contract stated that “the building of the sewer shall commence at Southern Boulevard as shown in the plan of work,” but the city did not in fact direct the work to be commenced at that point. It further appears with respect to this provision of the contract that the words “existing sewer in” had originally followed the words “commence at the,” and had been stricken out. The contract also, as before stated, stipulated that “no claim for damages shall be allowed in consequence of * * * the — 778 — adjoining sewer not being in the condition contemplated, * * * except that, if the contractor shall be delayed * * * by reason * * * of the adjoining sewer not being in such condition, such allowance of time shall be made,” etc. Furthermore, the contract distinctly provides: “The contractor at his own expense shall keep all the trenches * * * free from water, and. shall provide and keep in operation a steam pump or pumps * * * when notified so to do. * * * The contractor shall at his own expense pump out or otherwise remove any water which may be found or shall accumulate in the trench, and shall form all dams or other works necessary for keeping the excavation clear of water during the progress of the work.” We think,-therefore, that the plaintiff failed to show that it was contemplated by the parties and agreed that he should have the right and privilege of using a sewer at the intersection of East 187th street and 'the Southern Boulevard, even though the maps indicated that there was a finished sewer at that point. No harm was done the plaintiff by the exclusion of the evidence which he offered as to the meaning of the maps, because such evidence would merely have been cumulative, the engineer for the city having testified that the maps did indicate a finished sewer in the Southern Boulevard. The contract contains no provision that the plaintiff should have the right .to use a sew.er at that or any other point for drainage, and no representation, ■so far as the evidence shows, was made that there was a sewer properly -connected and leading to a place to.which the drainage might flow. From the fact that the Southern Boulevard was not graded, it would seem that the plaintiff should have been apprised that no sewer was in operation there. The provision in the contract was .that at his own expense the contractor should provide a pump and keep the trench clear of water. And, apart from the question -as to whether it was or was not represented that a sewer was in Southern Boulevard, there was neither contract nor representation by the city that the contractor could use it or that it was fit and suitable for drainage. "In other words, the city entered into no contract, express or implied, that it would supply a sewer that would drain off the water, but, on the contrary, the contractor agreed to supply the necessary pumps and facilities for that purpose. It follows, in our opinion, that the plaintiff has no basis for claiming damages for the cost of pumping, and the failure of the city to supply him with a serviceable sewer for drainage, and that the trial court properly dismissed the third cause of action, and the judgment so -entered should be affirmed. It will be unnecessary to more than briefly refer to the fourth and fifth causes of action. The former related to loss of profits on rock -excavation, which work was performed by another contractor, and the amount demanded was $869. This claim .was, upon the evidence, submitted to the jury., and their verdict in plaintiff’s favor for the sum of $600 is, we think, upon this subject, conclusive as to the rights of the parties. The fifth cause of action was for -damages alleged- to have been sustained by the city’s requiring, during a part of the time the work was progressing, that the contractor should restrict his laborers to — 779 — eight hours a day. It appears that this was in accordance with the terms of his contract; and it follows that the plaintiff had no standing to recover for not being permitted, in violation of his agreement, to work more than eight hours, a day. We think, therefore, that the trial court was right in dismissing this cause of action. Our conclusions upon the whole case are that the judgment and order denying motion for new trial should be reversed, and a new trial ordered, with costs to appellant to abide event. The appeal from the order denying motion for reargument should be dismissed, with $10 costs. VAN BRUNT, P. J„ McLAUGHLIN and LAUGHUIN, JJ., concur.