Cook v. McCabe

Cassoday, J. Neither party offered to furnish materials, and rebuild and restore the portions of the building destroyed by the fire. On the contrary, each insisted upon the other suffering the loss. A large nunibér of cases are cited in support of the proposition ' that in case of an entire and indivisible contract for the building of a house for a specified sum, to be paid on its completion, and where the edifice is destroyed by fire during the progress of the work, the builder must bear the loss and be to the expense of repairing the damages. The principle underlying the proposition contended for, to a certain extent, is undoubtedly correct. In Brecknock Canal Co. v. Pritchard, 6 Durnf. & East., 750, the bridge which the contractor agreed to build was . broken down by an extraordinary flood, and Kenyon, O. J., said: “If the defendants had chosen to except any loss of any kind, it should have been introduced into the contract by way of exception.” So it was held, on the authority of Lord Chief Justice Hale," that “ the lessee of a house, who covenants generally to repair, is bound to rebuild it if it be burned by an accidental fire.” Bullock v. Dommitt, id., 650. See Walton v. Waterhouse, 2 Saunders, 420; S. C., C Keble, 40; 2 Williams’ Notes to Saunders’ R., 826; McKenzie v. McLeod, 10 Bing., 385; Phillyps v. Stevens, 16 Mass., 238; Dermott v. Jones, 2 Wall., 1; Kramer v. Cook, 7 Gray, 550. So it has been held that, “ where a contract is made to build and completé a building and find materials for a certain entire price, payable in installments as the work progresses, the contract is entire; and if the building, either by fault of the *255 builder ol* by inevitable accident, is destroyed before completion, the owner may recover back the installments he has paid.” School Trustees of Trenton v. Bennett, 27 N. J. L., 513. So it has been held that non-performance by a builder, under such an entire contract, was not excused by the destruction of the building by lightning. School District v. Dauchy, 25 Conn., 530. So, “ where a person contracted to build a house on the land of another, and the house was, before its completion, destroyed by fire, without his fault, it was held that he was not thereby discharged from his obligation to fulfil his contract.” Adams v. Nichols, 19 Pick, 275. Such cases are distinguishable from one where the contractor agrees to repair another’s house already built, and it burns before completion of the repairs. Lord v. Wheeler, 1 Gray, 282; Wells v. Calnan, 107 Mass., 517. But the case at bar is not one of an entire contract to complete an entire building. It is more like Brumby v. Smith, 3 Ala., 123, in which it was held that “ where a workman agreed to complete the carpenter’s work on a house, and to receive a certain sum on the completion of the work, his employer furnishing the materials, and the house and materials were destroyed by fire, without the fault of the workman, the house being in the possession of the employer, held, that the workman could not recover a pro rata compensation for the work actually done.” The opinion in that case is based upon Cutter v. Powell, 6 Durnf. & East, 320, and Menetone v. Athawes, 3 Burr., 1592. In Gutter v. Powell the sailor was to be paid the sum named, “ provided he proceed, continue, and do his duty on board for the voyage;” and that case, in the language of Allen, J., in Wolfe v. Howes, 20 N. Y., 200, “ is distinguishable in this, that by the peculiar wording of the contract it was converted into a wagering agreement, by which the party, in consideration of an unusually high rate of wages, undertook to insure *256 his own life, and to render, at all hazards, his personal services during the voyage, before the completion of which he died.” Lord Kenyon, in deciding Cutter v. Powell, refers to the peculiar terms of the contract, and says “ it was a kind of insurance.” Page 324. See Taylor v. Laird, 25 L. J. (Exch.), 329. In the other case refered to, Menetone v. Athawes, the shipwright took the ship to his own dock for repairs, the owner agreeing to pay a sum named for the use of the dock, and also for the repairs; and it was held that “ the value of repairs may be recovered though a ship be burnt in dock.” In Niblo v. Binsse, 3 Abb. N. Y. Ct. Ap. Dec., 375 (S. C., 1 Keyes, 476), it was held that, “ if the owner of a building contracts for labor upon it, he is under an implied obligation to have the building ready and in a condition to receive the labor contracted for; and if, before the work is completed, the building is destroyed by fire, without the fault of. the contractor, the owner is in default, and the contractor can recover for all that was done up to the time of the fire.” In that case, as well as this, the time of performance had been extended by the mutual assent of the parties to the contract. Schwartz v. Saunders, 46 Ill., 18, was a case where “ the plaintiff entered into a contract with the defendant to do the carpenter work and furnish the materials therefor upon a brick building; the mason work was to be done by another and independent contractor. After the brick work was nearly completed and a part of the carpenter work done, the brick walls were blown down. Held, that the loss as to the carpenter work fell upon the defendant.” The court properly distinguished the case from some of the cases cited above, on the ground that “ the plaintiff had not undertaken to erect and finish this building and deliver it.” In Rawson v. Clark, 70 Ill., 656, the contractors agreed to manufacture and put into a building then in process of construction, certain iron work, but were prevented from com *257 pleting their contract by the building being destroyed by fire without their fault; and the court held they could recover ,pro tanto, and without performing the balance of their contract. Hollis v. Chapman, 36 Tex., 1, was a case where the plaintiff, a carpenter, undertook to furnish materials and do the wood work necessary to finish defendant’s brick building, and to turn over the building, complete, by a given day, for a specified gross sum. "When the plaintiff had nearly completed the work, the building was destroyed by fire, without his fault; and the court held that the plaintiff was entitled to recover for the materials furnished and work done by him. Stress was there laid upon the fact that the contract was conditional — that is, dependent upon the execution of another contract; and hence it was held to be apportionable, and the contractor entitled to a pro rata pay for his work. Taylor v. Caldwell, 3 Best & Smith, 826, was' a case of destruction by fire of a music hall engaged for concerts, and it was held that both parties were thereby excused from performance, because the general rule requiring absolute performance “ is only applicable when the contract is positive and absolute, and not subject to any condition, either express or implied.” It was there also ■ held that, “where, from the nature of the contract, it appears that the parties must from the beginning have known that it could not be fulfilled, unless, when the time for the fulfillment of the contract arrived, some particular specified thing continued-to exist, so that, when entering into the contract, they must have contemplated such continuing existence as the foundation of what was to be done, there, in the absence of any express or implied warranty that the thing shall exist, the contract is not to be construed as a positive contract, but as subject to an implied condition that the parties shall be excused in case, before breach, performance becomes impossible from the perishing of the thing, without the default of the contractor. *258 In the case at bar, as stated, Cook, Brown & Co. were not to do any of the carpenter work, joiner work, painting or glazing, and only to perform so much of the stone, brick and mason work, and furnish so much of the materials therefor, as was not to be furnished and performed by McCabe, who expressly agreed to furnish upon the ground all the sand and stone and twenty-four barrels of lime, and to haul all the brick, and to furnish all good suitable materials. It is evident from the contract that the materials for the mason work and the labor thereon were to be furnished and performed by Cook, Brown & Co. and McCabe, acting in conjunction with each other. The completion of the mason work, which was thus to result from their joint action, must necessarily have been dependent more or less upon the performance of the painting, glazing, carpenter and joiner work, with each and all of the persons doing the several kinds of work occupying the building, or portions of it, at the same time. With-much of the material and the land belonging to McCabe, and the materials • furnished by Cook, Brown & Co., together with the value of their labor thereon, becoming a part of the realty as 'fast as the same became attached to the soil, it would seem that no injustice can be done and no legal principle violated by treating the structure,, as far as completed, as the property of McCabe, especially as he so treated it himself, and got it insured for his own benefit, and when burned received the insurance therefor. The facts stated clearly distinguish the case from Jackson v. Cleveland, 15 Wis., 107, tad all the other cases cited by the counsel for the appellant, unless it is Brumby v. Smith, 3 Ala., 123; and that, in our judgment, is not sustained by principle or authority, and should therefore be disapproved. Upon principle, as well as the authorities cited, we are induced to hold that, (1) Where there is a positive contract to do a thing, not in itself unlawful, the contractor must perform it or pay damages for not doing it, although, in consequence of unforeseen accidents, the performance of his contract has become *259 Unexpectedly burdensome or even impossible. (2) But this rule’is only applicable when the contract is positive and absolute, and not subject to any condition, either express or implied. (3) Where, from the nature of the contract, it appears that the parties must, from the beginning, have known that it could not be fulfilled, unless, when the time for the fulfillment of the contract arrived, some particular specified thing continued to exist, so that, when entering into the contract, they must have contemplated such continuing existence as the foundation of what was to be done, there, in the absence of any express or implied warranty that the thing shall exist, the contract is not to be construed as a positive contract, but as subject to an implied condition that the parties shall be excused in case, before breach, performance becomes impossible frpm the perishing of the thing without default' of the contractor. (4)- Where, as here, one having nothing to do with the painting, glazing, carpenter or joiner work, contracts to furnish materials for the mason work of a building and perform the labor thereon, except that the owner, for whom the same is to be constructed, is to furnish upon the ground all the sand, stone; and a certain quantity of lime, and haul all the brick, and the building, not being in the exclusive possession of such contractor, just before completion, is destroyed by fire, without the fault of the contractor, the loss must fall upon the owner, especially where he has the same insured at the time for his benefit; and such owner cannot require the completion of the balance of the building without restoring the ■ parts which were so destroyed. With our construction of the contract, the defendant was entitled to sixty days within which to make payment of the balance of the contract’ price, without interest; but if he delayed payment for six months, then he agreed to pay seven per cent., and if one year, then ten per cent. These provisions for interest and an increase of interest were, in our opinion, merely to stimulate the defendant to pay promptly at the end *260 of sixty days, or, at the most, within six months, and not for the purpose of giving an absolute credit of one year. The measure of damages in such a case is, prvma facie, the pro rata share of the contract price. Trowbridge v. Barrett, 30 Wis., 661; Danley v. Williams, 16 Wis., 581. We are inclined to think that counsel for the appellant is right in contending that this was not a proper case for a foi’ced reference; but with our view of the law the court would have been authorized, upon the undisputed evidence, to direct a verdict for the plaintiffs; and as the amount, under such evidence, could not have been less than the amount found by the referee, the defendant has in no way been injured, and therefore, upon a well-established principle, we should not disturb the judgment. By the Court.— The judgment of the circuit court is affirmed.